Union Insulating & Construction Co. v. United States, 271 U.S. 121 (1926)

Please note: this case begins in mid-page. It therefore shares a citation with the last page of the previous case. If you are attempting to follow a link to the last page of 271 U.S. 109, click here.

Union Insulating & Construction Company v. United States

No. 263

Submitted April 21, 1926
Decided April 26, 1926
271 U.S. 121

APPEAL FROM THE COURT OF CLAIMS

Syllabus

1. Stipulations by the United States, in a construction contract, to furnish a right of way for ingress and egress to and from the places where materials to be furnished by the United States were stored and the place of their use in the work construed, in relation to other facts, as allowing the contractor to use a right of way on which was a railroad, but not as obliging the government to put the railroad in repair. P. 122.

2. Damages will not be awarded for a slight delay in starting work under a contract, not satisfactorily shown to have been caused wholly by the government, where the contractor made no protest at the time and no claim until nine months later. P. 124.

59 Ct.Cls. 582 affirmed.

Appeal from a judgment of the Court of Claims rejecting claims under a building contract.