Carnegie Steel Co. v. United States, 240 U.S. 156 (1916)

Please note: this case begins in mid-page. It therefore shares a citation with the last page of the previous case. If you are attempting to follow a link to the last page of 240 U.S. 142, click here.

Carnegie Steel Company v. United States


No. 171


Argued January 21, 1916
Decided February 21, 1916
240 U.S. 156

APPEAL FROM THE COURT OF CLAIMS

Syllabus

Ability to perform a contract is of its very essence, and delay resulting from absence of such ability is not due to unavoidable causes such as fires, storms, labor strikes, actions of the United States, etc., as enumerated in the contract involved in this action.

The fact that a contractor engaging to deliver armor plate of specified qualifications as to thickness, hardness, etc., was delayed by unforeseen difficulties in the then new art of manufacturing does not excuse performance if such delays were not within the excepted reasons for delay.

49 Ct.Cl. 391 affirmed.

The facts, which involve the construction of a contract for armor plate with the United States and the right of the contractor to recover sums withheld for delay in completion of the contract, are stated in the opinion.